Only written orders are accepted and imply full approval of all terms and conditions of sales hereunder. Opposite terms and conditions which could be stated on the order sheet or any other document would be considered as void, unless agreed by us on our acknowledgement of order.

Offers established by our representatives will only commit our company after written confirmation. Any order below 100 EUROS (Tax excluded) will be as of right increased by 10 EUROS.

The price charged will be the one in force at the date of invoice. They do not include the installation or starting of the equipment.

Any price discount granted at the date of sale or provision of service is directly linked to this specific operation (ord. of December 1st 1986, art. 31 al. 3, modified by the law dated July 1st, 1996)

Manufacturing times are given for information only, and a delay or a case of force majeure will not justify the cancellation of an order.

We reserve the right to effect, without previous notice, any technical modification to improve our products. Should a vehicle be modified by the manufacturer, we would supply the new bracket set under the new reference, and at a new price.

Only the terms of settlement stated on our offers and invoices will have to be taken into consideration. The drafts presented for acceptation will have to be sent back to us within 48 hours.

No discount will be granted for an advanced payment.

Any delay in settlement might give rise, as of right and without formality, to a refund of administrative and financial charges amounting to at least 1,5 times the legal interest rate.

Whatever the terms and conditions, the means of transportation or settlement, the transport of our products is effected at the consignee’s risks and perils. We would recommend to control the contents of each case upon receipt, in the presence of the delivery man. In case of lost or damage, reserves have to be stated on the delivery note, and confirmed to the haulier by registered mail with acknowledgement of receipt within 48 hours.

ACCORDING TO LAW N° 80-335 DATED MAY 12TH, 1980, AND TO ART. 121, AL. 2 OF THE LAW DATED 01-25-1985 PERTAINING TO THE EFFECT OF CLAUSES CONCERNING THE RESERVE OF OWNERSHIP IN THE SALES AGREEMENTS, AS WELL AS TO THE LAW DATED MARCH 31ST 2000 ABOUT THE CLAUSES OF RESERVE OF OWNERSHIP OPPOSABLE TO THE CREDITORS IN CASE OF BANKRUPCY, THE GOODS REMAIN OUR PROPERTY UNTIL FULL SETTLEMENT OF INVOICED PRICES.

THE TRANSFER OF OWNERSHIP TO THE BUYER OF THE PRODUCTS SOLD BY WORSHOP EQUIPMENT SYSTEMS SARL IS SUBMITTED TO THE INTEGRAL PAYMENT OF CORRESPONDING PRICE AT THE SETTLEMENT DATE

IN CASE OF NON SETTLEMENT BY THE BUYER, WORSHOP EQUIPMENT SYSTEMS SARL WILL BE ENTITLED, WITHOUT ANY PREJUDICE TO ALL THEIR OTHER RIGHTS, TO REQUIRE, BY REGISTERED MAIL WITH ACKNOWLEDGEMENT OF RECEIPT, THE RESTITUTION OF GOODS WHICH STILL REMAIN UNPAID, AT THE BUYER’S COSTS AND RISKS.

WORSHOP EQUIPMENT SYSTEMS SARL, MAY UNILATERALY AND IMMEDIATLY, HAVE THE LIST OF PRODUCTS WHICH REMAIN UNPAID AND HOLD BY THE CUSTOMER ESTABLISHED. IN THIS PURPOSE, THE CUSTOMER HAS TO MAKE SURE THAT THE IDENTIFICATION OF THE GOODS IS MADE POSSIBLE.

THE PRODUCTS IN THE WAREHOUSE WILL BE DEEMED AS BEING THE UNPAID ONES.

ALL LEGAL COSTS RELATED TO THE RETURN OF GOODS WILL BE AT THE BUYER’S EXPENSES.

WARRANTY:

— Our equipment is strictly guaranteed for two years, from the date of the sale to the final user, against any manufacturing defect. (Except for all electrical items for which the legal warranty period is one year). No warranty will be granted for rams and hand pumps made in Asia.

— Warranty includes the replacement or repair of parts which are considered by our technical department as being defective. It also includes corresponding manpower fees. The customer will be charged for transport costs only. The customer will in no case lay claim to the refund of complementary costs (travel, transport of the equipment) or to a compensation for immobilization, whatever the cause may be

— The return of goods not benefiting from a warranty right will only be accepted upon our previous written agreement, and implies the acceptation of the replacement or repair costs. Without any agreement from our company, the return of the equipment will not be effected within normal times

— The warranty right will not apply should a part be damaged further to an utilization which would not be in conformity with the technical specifications

of the product , or further to an incorrect installation or utilization

In no case the responsibility of WORSHOP EQUIPMENT SYSTEMS SARL. will be involved concerning demonstrations or starting of equipments. The owner of the workshop where this operation takes place, or who has lent the vehicle, is the only responsible person, towards the owner of the vehicle, for the possible repairs.

The customer remains the project manager and is responsible for civil engineering or building works which are necessary for the installation of the equipment.

The enforcement of above general terms and conditions of sales is governed by French legislation. In case of claim, the court of Vienne (Isère) France must be considered as being exclusively competent, even in case of several defendants or warranty claim.

WORKSHOP EQUIPMENT SYSTEMS Sarl. – 11 Rue du 11 Novembre - 38200 VIENNE FRANCE TEL : (33) 06 45 30 55 86 – E- MAIL : info@w-e-systems.com.